...damages or any exo-oS cost when the delay is due to unforeseeable causes beyond the control and without the fault or negligence of the contractor, including...quarantine restrictions, strikes, freight embargoes, and unusually severe weather but not including delays caused by .subcontractors : Provided further....

...excess cost when the delay in delivery is due to unforseeable causes beyond the control and without the fault or negligence of the contractor, including,...the Government, fires, floods, epidemics, quarantine restricReporter's Statement of the Case tions, strikes, freight embargoes, unusually severe weather,...

...any delays in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of the contractor, including,...God, or the public enemy, acts of the Government, including, but not restricted to any preference, priority or allocation order, acts of another contractor...

...Such causes include, but are 141 C. Cls. Opinion of the Court not restricted to, acts of God or of the public enemy, acts of the Government, fires, floods,...strikes, freight embargoes, unusually severe weather, and defaults of subcontractors due to any of such causes unless the Contracting Officer shall determine...

...of the contractor in making deliveries is due to unforeseeable causes beyond the control and without the fault or negligence of the contractor, including, but not restricted to, acts of God or of the public enemy, acts of the Government, fires, floods, epidemics, quarantine restrictions, strikes,...

...excess cost when the delay in delivery is due to unforeseeable causes beyond the control and without the fault or negligence of the contractor, including, but not restricted to, acts of God, * * * strikes * * * but not including delays caused by subcontractors. * * *. Article 15 further provides...

...because of any delay in completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of the contractor, including but not restricted to acts of the Government, acts of another contractor in performance of a contract with the Government, etc. It...

...unforesee*able causes beyond the control and without the fault or Reporter'i Statement of the Case negligence of the contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government, fires, floods, epidemics, quarantine restrictions, strikes,...

...failure Opinion of the Court to deliver was due to unforeseeable causes beyond the control and without the fault or negligence of the contractor, including but not restricted to numerous named causes among which was unusually severe weather. Between September 7, 1942, and September...

...delivery or performance when such failure or delay is due to causes beyond the control and without the fault or negligence of the Contractor, including but not restricted to (1) acts of God or of the public enemy, (2) acts of the Government of the United States or any State...